Liquidated Damages
Equitable Estoppel by Conduct and Silence Precluded Liquidated Damages
January 3rd, 2020
Retail owner and contractor had completed nine projects in two states. Most projects were completed beyond the original completion date, but no liquidated damages had been assessed. The current dispute concerned construction of five stores in Maine.…
Read More
Read More
Categories: Construction
Liquidated Damages Liability After Convenience Termination
April 20th, 2015
A contractor and public authority struggled through much of a pump station replacement project. During the work, the town agreed to extend the completion date by five months. Many change orders were presented and agreed to. The extended completion da…
Read More
Read More
Categories: Construction
About Stan Martin
Stan Martin holds a law degree and an undergraduate degree in architecture. He has been involved with the construction industry for more than 45 years, working in construction prior to law school and beginning his construction law practice. During his career, he has been actively involved with the Associated General Contractors of Massachusetts, the Boston Society of Architects, the American Arbitration Association, and the Massachusetts Building Congress.